Performance Bond Sample
A performance bond is a type of guarantee issued by a bank or an insurance company to ensure that a contractor fulfills its contractual obligations to the project owner. It provides financial security and reassurance to the owner in case the contractor fails to complete the project as agreed. Here is an English translation sample of a performance bond:
Contract No: [Insert Contract Number]
Date: [Insert Date]
To: [Insert Project Owner's Name]
[Insert Project Owner's Address]
We, the undersigned, hereby agree to provide a performance bond for the execution of the contract between [Insert Contractor's Name] (hereinafter referred to as "the Contractor") and [Insert Project Owner's Name] (hereinafter referred to as "the Owner"), as follows:
1. The performance bond shall be issued in favor of the Owner in the amount of [Insert Bond Amount in Words] ([Insert Bond Amount in Numbers]).
2. The performance bond shall remain valid and binding from the date of issuance until the completion of the contract and the issuance of the final acceptance certificate by the Owner.
3. In the event of the Contractor's failure to fulfill any of its contractual obligations, the performance bond shall be invoked by the Owner to compensate for any delay, damages, or losses incurred as a result.
4. The liability of the issuer under this performance bond shall be limited to the bond amount specified herein.
5. This performance bond shall not be terminated or revoked without the written consent of the Owner.
6. Any disputes arising out of or in connection with this performance bond shall be settled through amicable negotiations. In the event of failure to reach an amicable settlement, the disputes shall be referred to arbitration in accordance with the rules of [Insert Arbitration Institution]. The language of arbitration shall be English.
7. This performance bond shall be governed by and construed in accordance with the laws of [Insert Governing Law].
[Insert Issuing Bank's Name]
[Insert Issuing Bank's Address]
[Insert Issuing Bank's Contact Details]
[Insert Contractor's Name]
[Insert Contractor's Address]
[Insert Contractor's Contact Details]
[Insert Project Owner's Name]
[Insert Project Owner's Address]
[Insert Project Owner's Contact Details]
相关新闻： 银行保函风险案例 保险公司银行保函 银行投标保函如何注销 工程保函审批条件 工程款开银行保函 预付款保函开的了能撤回吗 成都市建设工程保函 建筑工程预付款保函的收费 投标保函怎么写 开具银行保函心得 银行工程履约保函的版本 国资委关于银行保函 银行保函公章 银行保函证明 履约保函的索赔情形是什么 工程保函延期报告 银行质量保函格式 投标保函从什么时间算起 国外银行会开保函吗 银行保函保证金的账务处理
